Terms and Conditions

Welcome to All Kitchens Fitted. These terms and conditions govern your use of our services and website. By engaging our services or accessing our website, you agree to comply with these terms.

1. Introduction

Please read these terms carefully before using our services.

2. Services

All Kitchens Fitted provides kitchen renovation and installation services. Our work is subject to availability, agreement, and compliance with these terms.

3. Quotes and Estimates

  • All quotes and estimates are valid for 30 days from the date of issue unless otherwise stated.
  • Final costs may vary if additional work or materials are required beyond the scope of the original quote.
  • Any changes to the agreed project scope must be documented and may incur additional charges.

4. Payments

  • A deposit is required before starting any project, as outlined in your contract.
  • Full payment must be made upon project completion or as per the agreed payment schedule.
  • Payments can be made via bank transfer or other approved methods.

5. Cancellations and Refunds

  • Cancellations must be made in writing at least 7 days before the project start date.
  • Refunds for deposits are subject to deductions for expenses already incurred.
  • We reserve the right to cancel services if terms are breached or unforeseen circumstances arise.

6. Liability

  • All Kitchens Fitted is not liable for delays caused by factors beyond our control, such as weather, supply chain issues, or customer delays.
  • We are not responsible for pre-existing structural issues or damages uncovered during the project.
  • Our liability for any claim is limited to the value of the contract.

7. Customer Obligations

  • Customers must provide clear access to the worksite and ensure the area is safe for our team.
  • Accurate project details must be provided, including measurements, preferences, and requirements.
  • Customers must ensure utilities (e.g., electricity and water) are available for project completion.

8. Warranty and Repairs

  • We provide a [specify duration, e.g., 12-month] warranty for workmanship from the project completion date.
  • Warranty does not cover wear and tear, misuse, or issues arising from third-party interference.
  • Any defects must be reported in writing within the warranty period for repairs.

9. Intellectual Property

  • All content on our website, including text, images, and designs, is owned by All Kitchens Fitted and is protected under copyright law.
  • Unauthorized use or reproduction of website content is prohibited.

10. Privacy and Data Protection

  • We collect and use customer data in accordance with our terms and Cookie Policy.
  • Your data will only be used for communication, service delivery, and legal compliance.

11. Use of Website

  • The website is provided for informational purposes only. We do not guarantee uninterrupted or error-free access.
  • Any unauthorized use of the website, including hacking or spamming, is prohibited.

12. Changes to Terms and Conditions

We reserve the right to update these terms and conditions at any time. Changes will be posted on this page, and continued use of our services constitutes acceptance of the revised terms.

13. Governing Law

These terms and conditions are governed by the laws of England and Wales. Any disputes shall be subject to the jurisdiction of the courts of England.

If you have any questions about these Terms and Conditions, please contact us:

Thank you for choosing All Kitchens Fitted for your kitchen renovation and installation needs!